T&Cs | elmsleygardenrooms

Elmsley Garden Rooms Terms and Conditions

Building Regulations

1.1 Meeting building regulations is the joint responsibility of the builder and the landowner, not of the supplier (us), nevertheless we want to make it clear that our products are not intended to be used where building regulations are required, so we have set out circumstances below so that you can easily check whether or not building regulations are likely to apply to you. By purchasing this product, the customer agrees with all of the following statements:

1.2 The building will contain NO sleeping accommodation

1.3 If the building is over 15 square metres in internal floor space then it will need to be positioned at least 1m away from any boundary, and contain no sleeping accommodation or; Please ensure that you speak with your Local Authority Building Control prior to purchase with regards to potential appropriate fire proofing.

1.4 If the building is over 30 square metres in internal floor space then you are made aware that this building does not comply with building regulations exceptions or you intend to use it for an exempted use such as: a building into which people do not normally go, or agricultural purposes, or you intend to modify the building, once installation is complete, in such a way that it will meet building regulations and understand that such modifications may invalidate any guarantees in the product.

1.5 If you are unsure about Building Regulations we recommend that you seek further advice and guidance from your local Building Control Office.

Terms and Conditions for Elmsley Garden Rooms Last updated: 10/11/2024

Welcome to Elsmley Garden Rooms. By engaging our services, you agree to the following terms and conditions. These terms govern the supply, installation, and fitting of garden rooms by Elmsley Garden Rooms and constitute a legally binding agreement.

2. Definitions

(a) “Company” refers to Elmsley Garden Rooms.
(a) “Customer” refers to the person or entity entering into this agreement with the Company.
(a) “Products” refer to the garden rooms and all associated materials supplied by the Company.
(a) “Services” refer to the delivery, installation, and fitting of the garden rooms.

3. Quotations and Orders

(a) All quotations provided by the Company are valid for 30 days unless stated otherwise.

(b) Acceptance of a quotation constitutes a binding agreement to purchase the Products and Services outlined within it.

4. Payments

(a) Payment terms are as follows:

(b) Deposit of 50% on order and a further 25% when water tight the final 25% is paid when we are finished the job.
(c) Late payments may incur interest as specified by Barclays base rate at the time.

5. Delivery and Installation

(a) Delivery dates are estimates and may be subject to change due to factors beyond the Company’s control, such as weather or supply chain delays.
(b) The Customer must provide suitable access to the property and ensure the area for installation is prepared as agreed.
(c) Any delays caused by the Customer in preparing the site may result in additional charges.

6. Installation Conditions

(a) Elmsley Garden Rooms requires a clear, level base for installation. Any additional work required to prepare the site beyond what was agreed in the quotation will incur additional charges.

(b) The Customer is responsible for obtaining any necessary planning permissions or regulatory approvals. The Company will not be liable for installations where permissions were not obtained.

7. Warranties

(a) The company offer a lifetime structure guarantee on all our rooms with 1-35 year warranty on other products from the date of installation.
(b) This warranty does not cover:
(c) Damage caused by misuse, accidents, or natural wear and tear.
(d) Damage due to incorrect site preparation or structural issues unrelated to the Company’s Services.
(e) Any claims under warranty must be made within 30 days of identifying the defect.

8. Liability

(a) Elmsley Garden Rooms shall not be liable for any indirect, incidental, or consequential losses arising from the use of its Products or Services.
(b) The Company’s total liability shall be limited to the amount paid by the Customer for the Products and Services under this agreement.

9. Cancellation and Refunds

(a) Deposits are non-refundable

10. Force Majeure

(a) Elmsley Garden Rooms shall not be liable for any delay or failure to fulfill its obligations due to circumstances beyond its control, such as acts of nature, strikes, or supply chain disruptions.

11. Governing Law and Jurisdiction

(a) These Terms and Conditions shall be governed by and construed in accordance with the laws of United Kingdom and any disputes shall be subject to the exclusive jurisdiction of the courts of Liverpool, England.

12. Entire Agreement

(a) These Terms and Conditions constitute the entire agreement between the Customer and the Company and supersede any prior agreements or understandings.

For questions about these Terms and Conditions, please contact us at Elmsley Garden Rooms.
Email: elmsleygardenrooms@gmail.com

Tel: 07535 512 178

Elmsley Garden Rooms Terms and Conditions

​